Wave Legals 04-11-18
Apr 11, 2018 | 94 views | 0 0 comments | 2 2 recommendations | email to a friend | print
PUBLIC NOTICE REQUEST FOR BIDS

Owner: Heber City Corporation

Address: 75 North Main, Heber, Utah 84032

BIDS for the Construction of the Heber City – 2018 Concrete Repairs project will be received by Heber City from bidders. Bids will be publicly opened and read aloud at 2:30 pm on Thursday, April 19, 2018, at the Heber City Offices located at 75 North Main, Heber, Utah 84032.

PROJECT DESCRIPTION:

The project consists of performing various concrete repairs and replacements in Heber City, Utah including approximately 10,000 square feet of sidewalk installation or replacement, approximately 200 lineal feet of curb and gutter replacement, and other miscellaneous repairs including trip hazard removal using concrete cutting or grinding.

Copies of the CONTRACT DOCUMENTS may be obtained at the Heber City Engineering office located at 75 North Main, HEBER, UTAH 84032 upon payment of $10.00 for each set, none of which will be refunded. Copies of the CONTRACT DOCUMENTS may also be obtained by requesting a copy via email at no charge. Date of availability is April 11, 2018.

Heber City will maintain a Plan Holders List of Bidders who request the CONTRACT DOCUMENTS directly from Heber City and who provide the required contact information. Any notices regarding changes/addenda to the CONTRACT DOCUMENTS will be sent via email to the Plan Holders. Bidders are responsible to provide and maintain accurate contact information with the City.

Heber City Corporation reserves the right to accept or reject any or all proposals, or any part of any proposal, including the right to waive any informality in any part of any proposal within the best interest of Heber City.

Published in The Wasatch Wave April 11 and 18, 2018.

HEBER CITY

CORPORATION

Planning Commission

Public Hearing Notice

Notice is hereby given that the Heber City Planning Commission will hold a public hearing on Thursday, April 26, 2018 at 6:00 p.m. in the Heber City Office Building, 75 North Main Street, South door, in the Council Chambers upstairs, to consider the following:

• Public Hearing to amend Heber City Municipal Code Section 18.28.030 Permitted Uses in the C-2 Commmercial Zone to permit Kennels and Animal Daycare

Public comment is welcome. Text and/or maps of proposed amendments can be viewed at the Heber City Office Building, Planning and Zoning Office, 75 North Main Street. Any questions or written comments pertaining to this Public Hearing can be directed to Karen Tozier or the Planning and Zoning Department (435-654-4830) during regular business hours or emailed to ktozier@ci.heber.ut.us.

Karen Tozier

Planning Commission

Secretary

Published in The Wasatch Wave April 11, 2018.

MIDWAY CITY NOTICE OF PENDING ORDINANCES

Notice is hereby given by Midway City, Utah, that a proposed ordinance is currently pending and under consideration by the Midway City Council and/or the Midway City Planning Commission for the following:

1. Midway City is proposing an Ordinance that would regulate, restrict or place conditions upon the construction, installation, maintenance and use of high voltage electrical power transmission lines (46 KV and above) within the boundary of Midway City, and related matters. More specifically it would restrict high voltage electrical power lines to the locations they currently exist with the city, and restrict the height of the poles to those historically established.

A copy of the proposed Ordinance is available in the Midway City Offices during normal business hours. ALL FUTURE APPLICATIONS FOR DEVELOPMENT APPROVAL AND/OR CONSTRUCTION, INSTALLATION, MAINTENANCE AND USE OF HIGH VOLTAGE ELECTRICAL POWER LINES WITHIN THE BOUNDARIES OF MIDWAY CITY WILL BE SUBJECT TO THE TERMS OF ANY AMENDMENTS TO THE CURRENT PROVISIONS OF THE MIDWAY CITY CODE.

All applicants are hereby notified that the acceptance for filing and processing of any applications for development approval by Midway City will not create any vested rights, equitable issues or legal claims against Midway City. The applicant further acknowledges receipt and review of a copy of this Notice of Pending Ordinance and further understands and agrees that the acceptance for filing and processing of any application for development approval will be subject to any amendments to the Midway City Code currently pending and under consideration by the Midway City Council and/or the Midway City Planning Commission.

Published in The Wasatch Wave April 11 and 18, 2018.

PUBLIC MEETING TIME CHANGE

Public Notice is hereby given that the Wasatch County Solid Waste Disposal District will hold regular meetings the 2nd Tuesday of each month at the Wasatch County Administration Building 25 North Main, Heber City, Utah at 3:00 pm.

January 9, 2018

February 13, 2018

March 13, 2018

April 10, 2018

May 8, 2018

June 12, 2018

July 10, 2018

August 14, 2018

September 11, 2018

October 9, 2018

November 13, 2018

December 11, 2018

AMENDED NOTICE

Published in The Wasatch Wave April 11, 2018.

NOTICE TO CONTRACTORS

Sealed proposals will be received by Wasatch County, at the office of Brent Titcomb, County Clerk, 25 North Main, Heber, Utah, 84032 until 2:00 p.m., April 24, 2018 for the 2018 Countywide Chip Seal Project in Wasatch County. Bid will be addressed to Brandon Cluff, Road Supervisor for Wasatch County at the above address.

The project consists of approximately 125,000 Square Yards of Chip Seal Coat, 170 tons of Emulsified Asphalt LMCRS-2 and miscellaneous Pavement Marking Paint.

The entire project is to be completed in 30 Working Days.

Proposal forms, plans, and specifications are on file and may be examined at the following locations:

Wasatch County Public Works Department, 1891 West 3000 South, Heber, Utah, 84032, Phone (435)654-1661

CIVCO Engineering, Inc., 1256 West 400 South Suite 1, P.O. Box 1758, Vernal, Utah 84078 Phone (435)789-5448.

Specifications, proposal forms, and plans may be obtained only from CIVCO Engineering, Inc. at the above location for a fee of $50.00 per set or electronically at no charge.

Each bidder must submit a bid bond from an approved surety company on forms provided by the surety company; or in lieu thereof, cash, certified check, or cashier’s check for not less than 5% of the total amount of the bid, made payable to the Wasatch County as evidence of good faith and a guarantee that if awarded the contract, the bidder will execute the contract and finish the contract bonds as required. The right to reject any and or all bids is reserved.

Dated the 30th day of March 2018

Mike Davis, County Manager

Wasatch County

Published in The Wasatch Wave April 4, 11 and 18, 2018.

NOTICE TO CONTRACTORS

Notice is hereby given that Wasatch County School District, 101 East 200 North, Heber City, Utah 84032, (435) 654-0280, fax (435) 654-4714, is accepting Bids for the following project:

Wasatch County School District – Asphalt Maintenance

Bids shall be submitted in accordance with the Plans and Specifications. These documents may obtained after 9:00 a.m., April 4, 2018. To obtain documents or ask questions during the bidding phase, email purchasing@wasatch.edu.

The scope of work is provided in the Specifications. Bids are due no later than 2:00 p.m., April 18, 2018, at the Wasatch County School District Office. By submitting a bid on this project, each offeror certifies that they are in compliance with all current laws and government regulations and are using the electronic verification system (e-verify) to confirm the work eligibility status of all workers hired on or after July 1, 2009. A 5% bid bond is required with each bid. The successful contractor will be required to submit a 100% payment and performance bond before work begins.

The Board of Education of Wasatch School District reserves the right to accept or to reject any or all proposals, or waive any informality in a proposal.

Published in The Wasatch Wave April 4 and 11, 2018.

NOTICE OF PUBLIC

MEETING

Notice is hereby given that the MIDWAY CITY PLANNING COMMISSION will hold a meeting on Wednesday, April 18, 2018 at 7 p.m. in the Midway Community Center, located at 160 West Main Street, Midway, Utah, to consider the following items:

1. Midway City is proposing a Code Text Amendment of Midway City’s Land Use Code of Title 16.13.10 regarding restrictions for transmission lines. The City would like to adopt restrictions that would govern the height and other items for transmission lines built in the City.

2. Jeremy Clark, agent for Snake Creek Partners LLC, is requesting a Plat Amendment of the Lodges at Snake Creek. The current plat contains 24 units, spread between three buildings, that have not yet been constructed. The amendment would reconfigure the 24 units into a mix of four-plex and duplex townhome style buildings. The property is located at the northwest corner of the intersection of Cari Lane and Pine Canyon Road and is located in the R-1-15 zone.

3. Karl Probst is applying for a Conditional Use Permit for an alcohol dispensing establishment. The restaurant will be called The Corner Restaurant and is located at 195 West Main Street. The property is 0.28 acres in size and is located the C-2 zone.

4. Luster Development, agent for Tom and Linda Whitaker, is proposing preliminary approval of the Whitaker Farm Subdivision. The proposal consists of 50 lots on 80 acres and contains 20 acres of open space. The property is located at 455 North River Road and is in the RA-1-43 zone.

Midway City is happy to provide reasonable accommodations for individuals with disabilities. For assistance, please call (435) 654-3223.

Published in The Wasatch Wave April 4 and 11, 2018.

NOTICE OF PUBLIC

MEETING

Notice is hereby given that the MIDWAY CITY PLANNING COMMISSION will hold a work meeting on Wednesday, April 18, 2018 at 3 p.m. in the Midway Community Center, located at 160 West Main Street, Midway, Utah, to consider the following items:

1. Midway City is proposing a Code Text Amendment of Midway City’s Land Use Code of Title 16.13.10 regarding restrictions for transmission lines. The City would like to adopt restrictions that would govern the height and other items for transmission lines built in the City.

Midway City is happy to provide reasonable accommodations for individuals with disabilities. For assistance, please call (435) 654-3223.

Published in The Wasatch Wave April 4 and 11, 2018.

REQUEST FOR BIDS

Owner: Heber Valley Special Service District, (HVSSD)

Address: 1000 East Main, PO Box 427, Midway, Utah 84049

SEALED BIDS for the HVSSD Pothole and Locate the Sewer Pressure Line will be received by HVSSD at 1000 East Main, PO Box 427, Midway, Utah 84049 until 2:00 p.m., Wednesday, April 18, 2018 and then publicly opened and read aloud. Recommendation for award will be presented to the HVSSD Board at the April 24 Board meeting.

PROJECT DESCRIPTION:

Project includes:

• Locate approximately 16,500 feet of Class 50 Ductile Iron Pipe. It is anticipated that 24 potholes may be needed. Each pothole will require a survey marker installed and surveyed indicating the location of the survey pin and the depth to the located utility. The pothole locations should be frequent enough to accurately locate the underground pressurized sewer line for future Blue Staking.

The CONTRACT DOCUMENTS, consisting of Request for Bids, Information for Bidders, Information Required of Bidder, Status Verification System Affidavit, Measurements and Payments, Certificate of Non-Collusion, Bid, Bid Bond, Agreement, Payment Bond, Performance Bond, Notice of Award, Notice to Proceed, Change Order, General Conditions, Special Provisions, Specifications, Drawings, and Addenda, may be examined at the following locations:

HORROCKS ENGINEERS, 728 West 100 South, Heber, Utah 84032

Copies of the CONTRACT DOCUMENTS may be obtained at the office of HORROCKS ENGINEERS LOCATED AT 2162 West Grove Parkway, Suite 400 Pleasant Grove, Utah 84062, and HORROCKS ENGINEERS LOCATED AT 728 West 100 South, Heber, Utah 84032 upon payment of $25.00 for each set, none of which will be refunded. Electronic Copy are also available. Date of availability is March 28, 2018.

PRE-BID MEETING:

2:00 p.m, Wednesday, April 11, 2018 at HVSSD Administrative Office located at 1000 East Main, PO Box 427, Midway, Utah 84049.

DOCUMENTS REQUIRED AT BID OPENING:

1. Bid forms provided. (Sections 00200, 00300, and 00355)

2. Cashier or Certified check or bid bond made payable to Heber Valley Special Service District in an amount equal to at least five percent (5%) of the total amount of the bid. Bid bonds must be underwritten by a Surety Company approved by the U.S. Department of the Treasury. (Circular 570, latest edition).

DOCUMENT 00210 REQUIRED 24 HRS AFTER BID OPENING.

If all required documents are not provided, the bid may be disqualified.

Heber Valley Special Service District reserves the right to accept or reject any or all proposals, or any part of any proposal, including the right to waive any informality in any part of any proposal within the best interest of HVSSD.

Date: April 2018

Dennis Gunn

District Manager

Published in The Wasatch Wave March 28, and April 4 and 11, 2018.

NOTICE OF LIEN SALE

A public auction will be held on Saturday, April 14, 2018, at 11:00 a.m., located at Daniels Road Self Storage, 1670 South Daniels Road, Heber City, Utah, 84032. The contents of the following storage unit will be sold or otherwise disposed of:

K24 Morris Clift

Full mattress, box springs and rails. Two padded chairs. Sleeping bags. Golf clubs. Suitcase. Softball bat, glove and bag. Cooler.

Published in The Wasatch Wave March 28, and April 4 and 11, 2018.

IN THE FOURTH JUDICIAL DISTRICT COURT

IN AND FOR WASATCH COUNTY, STATE OF UTAH

ZB HOLDING COMPANY, LC., a Utah limited liability company; and derivatively for ZERMATT RESORTS, L.L.C., a Utah limited liability company, and LEGACY RESORTS, LLC, a Utah limited liability company,

Plaintiffs,

vs.

KENNETH C. PATEY, an individual; PALISADE HOLDINGS, LLC, a Utah limited liability company; PRAIA LLC, a Utah limited liability company; FULLER HERITAGE, LLC, a Utah limited liability company; ZERMATT RESORT, L.L.C., a Utah limited liability company; and DOES 1 through 10.

Defendants.

NOTICE TO APPEAR OR APPOINT COUNSEL

Civil No. 140500069

Judge Jennifer Brown

TIER 3

Pursuant to Rule 74(c) of the Utah Rules of Civil Procedure, Defendants, by and through counsel, hereby submit this notice for Plaintiffs Kenneth C. Patey, Palisade Holdings, LLC and Praia LLC “to appear personally or appoint counsel.” See Utah R. Civ. P. 74(c). Former counsel for Plaintiffs filed a Notice of Withdrawal on May 15, 2017, and Defendants now must appear personally or appoint new counsel. Pursuant to Rule 74(c), Defendants have twenty-one (21) calendar days from the publication of this notice to appoint counsel and have that counsel file a notice of appearance with the Court.

KIRTON MCCONKIE

/s/ Rod N. Andreason

Attorneys for Legacy Resorts, LLC

Published in The Wasatch Wave March 28, and April 4 and 11, 2018.

NOTICE OF TRUSTEE’S SALE

On the 30th day of April, 2018, at the hour of 11:00 a.m., of said day, on the front steps of the Main Entrance of the Wasatch County Courthouse, 1361 South Highway 40, Heber City, Utah, Daniel J. Torkelson, as Trustee, will sell at public auction, to the highest bidder, for cash, in lawful money of the United States, all payable at the time of sale, the following described property located in Heber City, Wasatch County, Utah, and more particularly described as follows:

Lots 44, 45, 49, 51, 52, 53, 54, 55, 56, 58, 59, 61, 62, 63, 65 and all Common Area in Beaufontaine PUD Phase 3, according to the Official Plat thereof on file and of record in the Wasatch County Recorders Office.

The Following Described Property Being the Proposed Plat of Beaufontaine PUD Phase 4. A parcel of land located in the Northeast Quarter of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian being more particularly described as follows: Beginning at a point located North 89°48’22” East 1019.74 feet along the North line of the North Quarter Corner of said Section 4 and South 1,679.63 feet; thence North 82°30’01” West 203.24 feet to a point of curvature with a 125.00 foot radius curve to the right; thence continuing 47.52 feet along the arc of said curve through a central angle of 21°47’00”; thence North 60°43’01” West 206.76 feet; thence South 29°16’59” West 50.00 feet; thence South 28°42’42” West 189.86 feet; thence South 22°36’17” West 289.28 feet; thence South 72°55’22” West 114.13 feet to a point on the arc of a 125 foot radius non tangent curve to the left; thence continuing 65.26 feet along the arc of said curve through a central angle of 29°54’47” (Chord Bears South 28°21’57” East 64.52); thence South 43°19’21” East 210.61 feet to a point of curvature with a 30 foot radius curve to the left; thence Continuing 47.12 feet along the arc of said curve through a central angle of 90°00’00” ; thence South 43°19’21” East 50.00 feet; thence North 46°40’39” East 564.60 feet to a point of curvature with a 175 foot radius curve to the left; thence continuing 119.66 feet along the arc of said curve through a central angle of 39°10’41”; thence North 07°29’59” East 48.92 feet to a point of curvature with a 30 foot radius curve to the right; thence continuing 47.12 feet along the arc of said curve through a central angle of 90°00’00”; thence North 7°29’59” East 50.00 feet to the point of beginning.

The following described property being the proposed plat of Beaufontaine PUD Phase 5. A parcel of land located in the Northeast Quarter of Section 4 Township 4 South, Range 5 East, Slat Lake Base and Meridian being more particularly described as follows: Beginning at a point located North 89°48’22” East 1252.06 feet along the North line of the North line of the North Quarter Corner of said Section 4 and South 1,636.84 feet; and running thence East 96.42 feet; thence South 00°00’59” East 36.73 feet; thence South 0°20’15” East 464.04 feet; thence West 173.02 feet; thence North 45°53’02” West 60.78 feet; thence West 81.26 feet; thence North 60°20’36” West 160.23 feet; thence North 43°19’21” West 74.10 feet; thane North 46°40’39” East 77.69 feet to a point of curvature with a 175 foot radius curve to the left; thence continuing 119.662 feet along the arc of said curve through a central angle of 39°10’41” ; thence North 07°29’59” East 48.92 feet to a point of curvature with a 30 foot radius curve to the right; thence continuing 47.124 feet along the arc of said curve through a central angle of 90°00’00” ; thence North 07°29’59” East 50.00 feet; thence South 82°30’01” East 50.51 feet to a point of curvature with a 175 foot radius curve to the right; thence continuing 121.812 feet along the arc of said curve through a central angle of 39°52’54”; thence North 50°39’26” East 56.07 feet to a point of curvature with a 90 foot radius curve to the left; thence continuing 79.598 feet along the arc f said curve through a central angle of 50°40’25” to the point of beginning.

The following described Property being the proposed plat of Beaufontaine PUD Phase 6. A Parcel of land located in the Northeast Quarter of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian, Being More Particularly described as follows: Beginning at a point located North 89°48’22” East 1351.23 feet along the North line of the North quarter corner of said Section 4 and South 2137.93 feet; and running thence South 00°20’15” East 497.29 feet; thence North 89°27’34” West 675.61 feet to a point of curvature with a 30 foot radius curve to the right; thence continuing 46.85 feet along the arc of said curve ;through a central angel of 89°28’58” thence North 00°01’24” East 106.01 feet to a point of curvature with a 30 foot radius curve to the right; thence continuing 45.45 feet along the arc of said curve through a central angle of 86°48’12”; thence North 03°10’25” West 50.00 feet; thence North 86°49’35” East 251.50 feet to a point on the arc of a 200.00 foot radius curve to the left; thence continuing 270.05 feet along the arc of said curve through a central angle of 77°21’47”; thence North 09°27’48” East 138.48 feet; thence South 45°53’02” East 60.78 feet; thence East 173.02 feet to the point of beginning.

The following Described Property Being the Proposed plat of Beaufontaine Phase 7. A Parcel of land located in the Northeast Quarter of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian being More particularly described as follows: Beginning at a point located North 89°48’22” East 1134.57 feet along the North line of the North Quarter Corner of said Section 4 and South 2094.89 feet; and running thence South 09°27’48” West 138.48 feet to a point of curvature with a 200 foot radius curve to the right; thence continuing 270.048 feet along the arc of said curve through a central angle of 77°21’47”; thence South 86°49’35” West 285.64 feet to a point of curvature with a 125 foot radius curve to the right; thence continuing 108.758 feet along the arc of said curve through a central angle of 49°51’04” thence North 43°19’21” West 50.70 feet to a point of curvature with a 30 foot radius curve to the right; thence continuing 47.124 feet along the arc of said curve through a central angle of 90°00’00”; thence North 46°40’39” East 486.91 feet; thence South 43°19’21” East 74.10 feet; thence South 60°20’36” East 160.23 feet; thence East 81.26 feet to the point of beginning.

The following described property being the proposed plat of Beaufontaine 600 South Road Dedication. A Parcel of Land located in the Northeast Quarter of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian, being more particularly described as follows: Beginning at a point located North 89°48’22” East 29.83 feet along the North line of the North Quarter Corner of Said Section 4 and South 2618.24 feet and running thence South 89°27’34” East 1324.37 feet; thence South 0°20’15” East 30.0 feet; thence North 89°27’34” West 1324.24 feet; thence North 0°35’29’ West 30.01 feet to the point of beginning.

Together with all permits, contracts, contract rights, licenses, construction contracts, architectural contracts, plans and specifications, governmental permits, fixtures, equipment, boilers, building materials, appliances, irrigation systems, goods, machinery, tools, office equipment, supplies, furnishings, furniture, inventory, accounts, instruments, documents, intangibles, chattel paper, general intangibles, and the proceeds and products of any of the foregoing, now or hereafter located on, or used or intended to be used in connection with, the real property described above, the construction of improvements on the real property described above, or the occupancy or use of the real property described above.

Said sale will be made without covenant or warranty regarding title, possession or encumbrances to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust, Assignment of Rents, Security Agreement and Fixture Filing executed by Beaufontaine Partners, LLC, a Utah limited liability company, as Trustor, in which Blackstone Capital, LLC, a Utah limited liability company, was named as Beneficiary, which was filed on September 25, 2015, as Entry No. 416555, in Book 1140 at Page 810, in the Records of the County Recorder of Wasatch County, Utah.

The current beneficiary of the Trust Deed is Blackstone Capital, LLC, a Utah limited liability company. The record owner of the property as of the recording of the Notice of Default was, and currently is, Beaufontaine Partners, LLC, a Utah limited liability company.

Bidders must be prepared to tender to the Trustee a $25,000.00 cashier’s check at the sale and a cashier’s check for the balance of the purchase price by 5:00 p.m., Mountain Time, on the date of the sale.

DATED this 28th day of March, 2018.

/s/ Daniel J. Torkelson

Daniel J. Torkelson, Trustee

COHNE KINGHORN, P.C.

111 East Broadway,

Eleventh Floor

Salt Lake City, UT 84147-0008

Telephone: (801) 363-4300

E-mail: dtorkelson@cohnekinghorn.com

Monday - Friday 8:30 a.m. - 5:00 p.m.

Published in The Wasatch Wave March 28, and April 4 and 11, 2018.

NOTICE OF TRUSTEE’S SALE

On the 30th day of April, 2018, at the hour of 11:00 a.m., of said day, on the front steps of the Main Entrance of the Wasatch County Courthouse, 1361 South Highway 40, Heber City, Utah, Daniel J. Torkelson, as Trustee, will sell at public auction, to the highest bidder, for cash, in lawful money of the United States, all payable at the time of sale, the following described property located in Heber City, Wasatch County, Utah, and more particularly described as follows:

The following described property being proposed plat of Beaufontaine Phase 8. A Parcel of Land Located in the Northeast Quarter of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian, being more particularly described as follows: Beginning at a point located North 89°48’22” East 951.57 feet and South 1203.72 feet from the North Quarter Corner of Section 4, Township 4 South, Range 5 East, Salt Lake Base and Meridian; and running thence North 89°57’27” East 396.78 feet; thence South 00°00’59” East 432.39 feet; thence North 90°00’00” West 96.42 feet; thence North 0°00’59” West 21.04 feet to a point of curvature with a 110.00 foot radius curve to the left; thence continuing 115.62 feet along the arc of said curve through a central angle of 60°13’31” (Chord Bears North 30°07’45” West 110.37 feet); thence North 60°14’30” West 149.20 feet to a point on the arc of a 291.59 foot radius curve to the right; thence continuing 231.90 feet along the arc of said curve through a central angle of 45°33’58” (Chord Bears North 29°43’24” West 225.83 feet) to a point of curvature with a 745.09 foot radius curve to the right; thence continuing 45.57 feet along the arc of said curve through a central angle of 03°30’15” (Chord Bears North 04°30’46” West 45.56 feet) to the point of beginning.

Together with all permits, contracts, contract rights, licenses, construction contracts, architectural contracts, plans and specifications, governmental permits, fixtures, equipment, boilers, building materials, appliances, irrigation systems, goods, machinery, tools, office equipment, supplies, furnishings, furniture, inventory, accounts, instruments, documents, intangibles, chattel paper, general intangibles, and the proceeds and products of any of the foregoing, now or hereafter located on, or used or intended to be used in connection with, the real property described above, the construction of improvements on the real property described above, or the occupancy or use of the real property described above.

Said sale will be made without covenant or warranty regarding title, possession or encumbrances to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust, Assignment of Rents, Security Agreement and Fixture Filing executed by Beaufontaine Partners, LLC, a Utah limited liability company, as Trustor, in which Blackstone Capital, LLC, a Utah limited liability company, was named as Beneficiary, which was filed on October 31, 2016, as Entry No. 430759, in Book 1174 at Page 520, in the Records of the County Recorder of Wasatch County, Utah.

The current beneficiary of the Trust Deed is Blackstone Capital, LLC, a Utah limited liability company. The record owner of the property as of the recording of the Notice of Default was, and currently is, Beaufontaine Partners, LLC, a Utah limited liability company.

Bidders must be prepared to tender to the Trustee a $25,000.00 cashier’s check at the sale and a cashier’s check for the balance of the purchase price by 5:00 p.m., Mountain Time, on the date of the sale.

DATED this 28th day of March, 2018.

/s/ Daniel J. Torkelson

Daniel J. Torkelson, Trustee

COHNE KINGHORN, P.C.

111 East Broadway, Eleventh Floor

Salt Lake City, UT 84147-0008

Telephone: (801) 363-4300

E-mail: dtorkelson@cohnekinghorn.com

Monday - Friday 8:30 a.m. - 5:00 p.m.

Published in The Wasatch Wave March 28, and April 4 and 11, 2018.
Comments
(0)
Comments-icon Post a Comment
No Comments Yet